Skillbuild Construction Ltd – Terms and Conditions of Business
These Terms and Conditions set out the basis on which Skillbuild Construction Ltd undertakes brickwork and blockwork services for its clients. They apply to all quotations, contracts, and agreements for labour-only and supply-and-fix projects unless otherwise agreed in writing. By instructing Skillbuild Construction Ltd to proceed with works, the client acknowledges and accepts these Terms and Conditions in full.
1. Definitions
1.1 “Company”, “We”, or “Us” refers to Skillbuild Construction Ltd.
1.2 “Client” means the individual, firm, or company to whom the quotation is addressed and for whom the works are undertaken.
1.3 “Works” means the brickwork and blockwork operations, whether on a labour-only or supply-and-fix basis, described in the quotation or subcontract order.
1.4 “Contract” means the agreement formed between the Company and the Client comprising these Terms and Conditions, the quotation, and any written amendments agreed between both parties.
2. Scope of Works
2.1 The Company shall carry out the Works as detailed in the quotation or subcontract order in accordance with current Building Regulations and industry standards.
2.2 Any variations, additional works, or instructions altering the scope of the Works must be confirmed in writing and may be subject to additional cost and/or time.
2.3 The Company undertakes both labour-only and supply-and-fix contracts as specified in the quotation.
3. Quotation and Acceptance
3.1 All quotations remain valid for 30 days unless otherwise stated.
3.2 Acceptance of a quotation or instruction to proceed constitutes acceptance of these Terms and Conditions.
3.3 No variation or addition shall be binding unless confirmed in writing by the Company.
4. Programme and Site Access
4.1 The Client shall provide the Company with safe and continuous access to the site to enable the Works to be carried out efficiently.
4.2 The Company shall not be liable for any delay, loss, or expense arising from restricted access, adverse weather, delay by others, or circumstances beyond its control.
4.3 Any agreed programme dates are subject to revision where such events occur.
5. Health and Safety
5.1 The Company operates in accordance with the Health and Safety at Work Act 1974 and associated regulations.
5.2 The Client shall ensure that the site is safe, properly prepared, and that adequate welfare facilities and scaffolding are provided prior to commencement of the Works.
5.3 The Company will supply Risk Assessments and Method Statements (RAMS) where required.
6. Payment Terms
6.1 Payment shall be made within 28 days of invoice unless otherwise agreed in writing.
6.2 Interim applications for payment may be submitted monthly where the duration of the Works exceeds one month.
6.3 Retention shall be deducted at standard industry rates where applicable and released in accordance with the main contract provisions.
6.4 The Company reserves the right to suspend the Works for non-payment in accordance with the Housing Grants, Construction and Regeneration Act 1996.
7. Variations
7.1 No additional or varied work shall be undertaken without prior written confirmation from the Client.
7.2 Variations will be valued at agreed rates or, where no rates exist, on a fair and reasonable basis.
7.3 Any agreed variations may result in adjustments to both cost and completion period.
8. Materials and Ownership
8.1 Where materials are supplied by the Company, they shall remain the property of the Company until paid for in full.
8.2 Once incorporated into the Works, ownership shall pass to the Client.
8.3 The Client shall provide secure and dry storage for all materials delivered to site by the Company.
9. Insurance
9.1 The Company maintains the following insurance cover:
– Public Liability Insurance – £5,000,000
– Employers’ Liability Insurance – £10,000,000
9.2 Proof of insurance can be provided upon request.
10. Defects and Quality
10.1 The Company shall carry out the Works with reasonable skill and care and in accordance with good trade practice.
10.2 Any defects due to faulty workmanship for which the Company is responsible shall be made good within a reasonable period, provided written notice is received within 12 months of completion.
10.3 The Company shall not be liable for damage or defects arising from misuse, neglect, or interference by others.
11. Termination or Suspension
11.1 The Company may suspend or terminate the Works where:
– Payment is not made by the due date;
– The site is unsafe or access is withdrawn; or
– The Client commits a material breach of contract.
11.2 Either party may terminate this Contract upon written notice if the other becomes insolvent or ceases trading.
12. Liability
12.1 The Company’s total liability under this Contract shall not exceed the total Contract value.
12.2 The Company shall not be liable for indirect, consequential, or economic losses, including loss of profit or delay caused by others.
13. Dispute Resolution
13.1 Any disputes shall first be referred to senior representatives of both parties for resolution.
13.2 Failing agreement, either party may refer the matter to adjudication in accordance with the Housing Grants, Construction and Regeneration Act 1996.
14. Governing Law
This Contract shall be governed by and construed in accordance with the laws of England and Wales, and the parties submit to the exclusive jurisdiction of the English courts.
Skillbuild Construction Ltd
Director: Damien Roughley
